Loading...
REVIEWED BLD2021-1065+Scope of work & Contract+7.31.2021_2.39.47_PM+2332255RECEIVED Aug 02 2021 HOME IMPROVEMENT CONTRACT ciof E DEVELOPMENT OPMENTT SSERVI ERVICES THis AGREEMENT, DATED I I-f �i, '_.4 , IS BETWEEN: DEPARTMENT The Notice of Cancellation may be mailed to the address of the contractor as shown below: BLD2021-1065 ------- � a " G t'_. `.I_., AND L 7c-6.. 5o (.k,�•� (Contractor's Name) (owner's Name) CA6� r0hr:,1 I. Z-tti cam. ...... (job Adders) .,.,.,.,.,.,.,.,.,.,.,.,.,.,.,.,.,.,., _ REVIEWED (Contretor's License Number) BY (Conractor's Address) (C hy, State & Zip) .', ----,—!-CITY OF EDMONDS 10ty, State & Zip) (Home Telephone) (Work elephone ZS2, r ) tti(_ p' UI C - (vl - i71 l+fi ti S :� BUILDING DEPARTMENT (Contractor's Telephone) (Cell Phone) (Fax Number) ,,,, ,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,,; Description of the Project and Description of the Significant Materials to be Used and Equipment to be Installed: Contractor will famish all labor and materials to construct and complete in a good, workmanlike and substantial manner: SEE ATTACHED CONTINUATIONIADDll FOR DESCRIPTION OF WORK NOT INCLUDED: The following items are specifically excluded or are to be provided by Owner. NOTE: Entire agreement is contained herein. NO ORAL REPRESENTATION shall be considered part of this contract unless listed in writing. . , .. Approximate Start Date: Approximate Completion Date: i�1 z ' All start and completion dates are approximate. (See additional terms and conditions on reverse side). The work to be performed under this contract shall be commenced on approximate start date as long as any required building permits are received and any agreed upon funds are paid to Contractor. The project will be completed by approximate completion date subject to permissible delays. CONTRACT PRICE: $ '_ , .J,.i DOWN PAYMENT: $ i 000 (6wner agrees to pay Contractor total cash price) (if any; if not applicable, put "none") Contract price is subject to additions and deductions pursuant to changes agreed upon in writing by the parties and subject to allowances. THE DOWN PAYMENT MAYNOT EXCEED $1,000 OR 10% OFTHE CONTRACT PRICE, WHICHEVER IS LESS. SCHEDULE OF PROGRESS PAYMENTS: The schedule of progress payments must spectfically describe each phase of work, including the type and amount of work or services scheduled to be supplied in each phase, along with the amount of each proposed progress payment. IT IS AGAINST THE LAW FOR A CONTRACTOR TO COLLECT PAYMENT FOR WORK NOT YET COMPLETED OR FOR MATERIALS NOT YET DELIVERED. HOWEVER,A CONTRACTOR MAY REQUIRE A DO WNPAYMENT. (Work or Services to be Performed or Materials [o be Supplied) AMOUNT I �] a Upon satisfactory payment being made for any -- 2. - �, _ u �� �tl i ur $ i� 9` _ portion of the work performed, the contractor ' ~ [ $ shall, prior to any further payment being made, 3. fumish to the person contracting for the home 4. ��- $ l7d 0 - improvement work a full and unconditional release from any claim or mechanic's lien pursu- g. $ ant to Section 3114 of the Civil Code for that portion of the work for which payment has been 6, $ made. Contractor may, if requested, refer owner to a finance company, but any negotiations or arrangements between owner and finance company is owners sole responsibility. Unless specifically stated above that this Agreement is subject to approval of financing, this Agreement is not subject to obtaining or approval of financing. List or Documents to be incorporated into the Contract: Notice Concerning Commercial General Liability insurance (CGL); Notice Concerning Worker's Compensation ]nsurance; Arbitration of Disputes; Notice of Cancellation; Three -Day Right to Cancel; Mechanic's Lien Warning; Information about Contractors' State License Board, Checklist for Homeowners. A nodee concerning Commercial General Liability Insurance is attached to this contract. A notice conccming Workers' Compensation Insurance is attached to this contract. (list any additional attachcmcnts): Owner acknowledges receipt of a fully completed copy of this agreement and all dofum0ts listed above; You (the owner or tenant) A R 8 1 T R A T 10 N have the right to require the '' RIGHT TO CANCEL Contractor to have a OWNER: Initial this box if performande and payment The law requires that the contractor give you you agree to arbitration. bond; however, the a notice explaining your right to cancel. Review the "Arbitration of Contractor can charge you Initial the checkbox if the contractor has given Disputes" section attached for the costs of procuring a bond. you a "Notice of the Three -Day Right to Cancel You are entitled to a completely filled in copy of this agreement, signed by both you and the contractor, before 1 any wgrk may be started." �j (Owner's Signature) (Date (Salesperson's Signature) (Date} X ,� _lr'1 r// q71 State Registration Humber 4.0 , HJ 22 L W 2- (Urnore than one Owner, please Sign Here) (Date) BY SIGNING ABOVE, OWNER ACKNOWLEDGES RECEIPT OF A COPY OF NOTICE TO OWNER: THIS AGREEMENT IS SUBJECT TO THIS AGREEMENTAND ALL ATTACHED DOCUMENTS HOME OFFICE APPROVAL BEFORE IT BECOMES EFFECTIVE CONTINUATION /ADDENDUM �t it '.1� P�iIECi: idIr o ui Grare d (C onlrao[er's NamelIl + (C,eteoe- Name) /Type or Prefect! (Adana. E� u, sub wa 9 j o2.-O {City. 6let e end Zlyj ` 7hia is a Can(inu etion or Addition to original Home Improvement Contract dated f ZI 7G 1N Hnme a WOr4 a Cell a ATTENTION ALL HOMEOWNERS It is illegal for any representatives to ask for checks to be issued in their names or to ask for cash. Please contact the Company Immediately should this happen to you. We will accept no responsibility for any checks issued to others. 'NOTE. price does not include permit fees unless specified below, it Icanenue Contre 1 ProVtlbn i r� c•Lr ri fLl.. ,f r',w: ua a t,�tya I� IA ry uI.4 a Is u���s ko ,u Batt L✓ Ia^F: rM,s.uni�JtaYrt u N iPrrl_ vU et u,,7(�r,lt Cl 3 k QL 1up w '�..�4:✓, c,v rc: u� — Cam. -�0 v U N - { i V YP 4✓ G. I o et r + et n -� k[" d cx It v s k_g d W.., h lidA-R- No.,r `t•L tv'r, —e - L, J e LJ .tu l-tligt Wt2. _ [ l I V �rs 0"✓nL. K�l���cy Yfe4 L( Sor c µr lihe.��.aa[r, 1 l -1 .r LA iva�l �toLM1iA-f Q'FII kr'rQ +,� aF Inn u'4YY�4f `: 'I r'l� C.P Q �.C.Su '� , u 0.,4.[/t1- S.¢✓ M A . I. S.-, _ � - � �,=K ?' J C.e. ..., � , a I'G .0 w f 4 Approximate Start Date `� ' ? " Approximate Date of Completion: TOTAL PRICE OF ABOVE $ S S , Down Payment $ i000 — Ilncu:ies �aeor aae Male ri al si Payment Schedule as Follows: ,., r, $ o ou - due upon 5 "f ��rH, �. �>a ��, tM Z0,000 - _ due upon S' Lµ D 3a due upon —�ui _..—._ I qJo - due upon t- k; due upon due upon le above continuation /addendum is subject to company approval. Customer understands that project could be delayed due to plans, permits, city requirements and additional work added to original contract, thus,all start and completion dates are approximate. Customer further understands that entire agreement is contained herein. No oral representation shall be considered part of this Contract unless listed in writing All o her terms and conditions stated in original contract to remain the same, Contractor Initials Customer's Signature f Date ! 'r r '.