Loading...
APPROVED BLD2022-0939+Architectural_Plan+7.14.2022_3.44.58_PM+2990722Tuesday, April 19, 2022 PROPOSAL CLIENT SITE ADDRESS CITY & STATE PHONE EMAIL City Of Edmonds Building Department ------------------------- Work FOUNDATION STABALIZATION Address, 22507 93RD PL W Owner MORRISON Approved Date _ 0 - - — — 0- - = _ _ Building Official: Erw Carter Permit Number B1 D2022-0939 David Mor FOUNDATION SPECIALIST 22507 93rd PI W Special Inspection orts to be provided Edmonds, WA, 98 ity Inspector. 206-999-3836 9 McDougall Ave STE 204 Everett, WA 98201 Damorrison999@gmail.com RECEIVED Jul 15 2022 CITY OF EDMONDS DEVELOPMENTSERVICES DEPARTMENT P: (425) 760-5077 WA# RRFOUFS829DA Piling Options Type Product gty Item Cost Extended Cost Helical Pile 3" Helical Pile 11 $1,900.00 $20,900.00 Hardware Additional Steel Angle Iron 6 $45.00 $270.00 _ Concrete Remove & Replace Holes 1 _ $180.00 $180.00 -1APPRC)VED E;� � �1y4 &d ST BE —EINSPECTIO 1 El SITE CODE COM-PUAN-CE -_ 4) Engineering and Permits Permits $1,067.50 $1,067.50 Structural Engineering _ $1,500.00 $1,500.00 Geo Engineering Proposal Good for 90 Days _ $23,917.50 Sales Tax Billed On Final Invoice TOTAL $23,917.50 SIGNATURE With my signature, I am confirming that I have read, reviewed and agreed to the proposal, job description, level survey, job photos and contract provided to me by R&R Foundation Specialist. Property Owner Name Property Owner Signature Ca ,e R&R Foundation Specialist Date Tuesday, April 19, 2022 JOB PHOTOS House Profile. remove and replace concrete in this area. Customer will remove stair stringer prior to install. RECEIVED Jul 15 2022 EDMONDS ENT SERVICES ,RTMENT Pier locations 1-4 Southeast foundation wall. Customer will remove 3 ft of deck boards prior to install in this area. remove deck boards at location 10 prior to install. RECEIVED Jul 15 2022 CITY OF EDMONDS DEVELOPMENT SERVICES DEPARTMENT Contract iFOUNDA710N -S511M LJST 1. R&R Foundation Specialist Terms and Conditions 1.1 Agreement These items and conditions (terms) govern the furnishing of construction services (services) R&R Foundation Specialist, LLC (hcrcinaftcr, "RRS") to the customcr idcntificd in the proposal which thcsc tcrms company (customcr). Thcsc terms together with the proposal furnished by RRS to the customer comprise the entire agreement between the parties and supersede any prior oral orwritten agreements relating to the services (contract). This contract may be modified only by the written agreement of the parties. 1.2 Scope of Work RRS will provide all services, materials equipment and labor necessary to complete the work described in the proposal furnished by RRS to the customer relating to the services. 1.3 Fees and Payment The customer will pay the fees as specified in the proposal according to the following payment schedule: twentyfive percent(25%) of the total fees shall be payable upon customers execution of this contract; anothertwentyfive (25%) upon receipt of engineering/permitting process; and all remainingfees shall be payable upon completion of the services. Any accrued balance owing and unpaid to RRS, regardless of whether the amount in dispute is liquidated or unliquidated, shall bear interest at 1.5% per month from the date payment becomes due. The customer shall reimburse RRS for all costs incurred in collecting any late payments including attorneys fees. RRS certifies, upon the customers complete payment of all fees due hereunder, that all material suppliers, labor and subcontractors utilized in performing the services will have been paid in full. Change order work will be agreed upon and billed independently from this contract. Remaining change order work will not delay payment of this contract. Time and Material rates: Hourly rates are billed at $95.00 per hour perworker. Material rates are contractors cost plus 20% mark up. 1.4 Customer Rights and Responsibilities The customer has the right to (a) receive the products and services agreed to in this contract; (b) resolve disputes through means outlined in this contract. The customer will provide to RRS (a) access to the worksite as when needed by RRS; and (b) all surveys and reports necessary to RRS to complete the project (e.g., engineering reports, maps of utility locations, and real property surveys). 1.5 Delays RRS will use reasonable efforts to meet any quoted performance dates but shall not be responsible for any delay in performance resulting from causes beyond its reasonable control, and the inability to obtain necessary labor or material from unusual source. In such event, RRS performance shall be excused for a commercially responsible time that is at least the length of time lost due to such delay. There will be mutually agreed upon start and end date, any potential delays will be fully communicated and mutually agreed upon. RECEIVED Jul 15 2022 CITY OF EDMONDS DEVELOPMENT SERVICES DEPARTMENT Contract FOUNDA710N SP6C7AL15T 1. R&R Foundation Specialist Terms and Conditions CONT. 1.6 Unanticipated Site Conditions If RRS encounters any of the following conditions at the worksite then it will immediately stop work and notify the customer of: (a) physical conditions that are materially differentfrom those conditions observed during RRS initial inspection of the site; or (b) unusual or unknown physical conditions that are materially different from those originally encountered and generally organized as inherit to work of the character provided for this contract. In such event RRS and the customer may terminate the contract, and mutually agreed to an equitable adjustment in the fees and/or performance schedule. After agreed, excess will be returned within 5 business days. (c) Typical footing thickness is 8-12 inches thick, additional cost and or added work scope may be necessary for the installation of designed pier. (d) Standard practice of slabs is typically 3-1/2 to 5-1/2 inches thick, additional cost will be necessary at time and material rates stated above if slab excides standard practice. 1.7 Changes in Work The customer may at any time request changes to the scope of services including additions or deletions, amendments to the drawings or specifications, or changes to the performance schedule. If any requested change will cause an increase in the cost or timing required to complete the services, then RRS will be entitled to an equitable adjustment in fees and/or performance schedule. RRS will promptly inform the customer of any such adjustments and initiate a change order. Such requests shall be made directly to RRS or to a lead person designated by RRS. Change orders should be reduced to a written change order signed by both Customer and RRS in order to avoid misunderstandings over cost or scope of the change order. Customer shall be obligated to pay RRS at RRS's hourly rates for the time preparing change orders that Customer later decides not to proceed with. If Customer accelerates the schedule of RRS's work, Customer shall be obligated to pay for any overtime labor performed by RRS at overtime rates. Customer may elect to use e-mail as written consent to authorize or approve a change order, in which case RRS may proceed as directed by Customer. Unless a change order has been prepared in writing with a fixed price, the cost of the change order shall be paid based on the time and materials formula on page one of this contract, regardless of whether the Customer selected the fixed price option for the original contract work. 1.8 Cancellation/Termination Except as otherwise provided by law, the customer may only cancel this contract if RRS consents in writing. In such event, the customer will pay RRS: (a) its actual cost for the portion of the services performed prior to the date of termination; (b) it's incurred costs of termination, including termination charges imposed by RRS' vendors and (c)twenty percent (20%) of all RRS actual and incurred costs for overhead and profit. If the customer or RRS becomes insolvent or commits a material breach of these terms, then customer or RRS may terminate this Contract without liability or penalty. 1.9 Disputes and Remedies A. Procedure If a dispute should arise between RRS and Customer, they shall promptly meet and attempt in good faith to resolve the dispute. Any unsettled disputes shall be decided by a suit filed in an appropriate court of jurisdiction unless RRS, and Customer mutually agree otherwise_ If suite is filed in Superior Court, the suit shall be decided mutually between customer and RRS according to the Mandatory Arbitration Rules Arbitrator (MAR) regardless of the amount in dispute and without limitation on the amount to be awarded by the Arbitrator. The MAR Arbitrator shall determine the validity and enforceability of a lien, if any, and the award shall not be limited by otherwise applicable MAR limits. RRS and Customer waive their right to a trial de novo (appeal) and further expressly agreeto accept the Arbitrators decision as binding and final. B. Attorney Fees In the event that a lawsuit is filed to enforce this contract, each party shall pay its attorney fees and costs. RECEIVED Jul 15 2022 CITY OF EDMONDS DEVELOPMENT SERVICES DEPARTMENT 9 \ FOUVIDATU M 5PECIALMT 1 Contract 1. R&R Foundation Specialist Terms and Conditions CONT. 1.10 Limited Lifetime Warranty RRS warranties the services performed for as long as the customer owns the property. This limited lifetime warranty does not cover defects or damages resulting from: carelessness, misuse, abuse, improper commercial use, or material modification to the pier or structure where attached; damage caused by slope failure, soil creep, earthquake, flood damage, etc. Warranties of each product RRS installs are backed by their manufacturers limited 75-year warranty. This warranty is not transferable unless the customer submits a transfer fee of S300 together with a signed copy of the application for transfer of limited lifetime warranty within 60 days of the transfer of title to the subject property. 1.11 Limitation of Liability The customer understand and agrees thatthe services are subject to, and RRS shall not be liable for, the following limitations: (A) Water leaks due to separation in plumbing may exist prior to performance of the services and may also occur as a result of the services. (B) RRS makes no representation regarding to any of leveling, fixing, or closing cracks. RRS will not lift any foundation beyond its practical limit unless the customer signs a waiver for excessive damages. This may be hindered by cosmetic repairs of previous damages. (C) If the scope of services includes installation of piers through concrete, the replacement of concrete may not match existing concrete. (©) Plants that are affected by excavation may not survive and RRS makes no warranty of any kind regarding the survival of affected plants. The customer may choose to hire a professional landscaperto remove and replace plants in order to improve their chance of survival.(E) The customer may choose to hire a landscaper to replace any stone, slate, or paver paths of any sort that are affected by excavation as RRS makes no warranty of any kind for replacement of such paths to their original condition. (F) The piers that may be installed by RRS are not designed to remedy or prevent upward movement of the foundation. It is the customers responsibility to take care of and RRS shall not be liable for the following items should there be a problem either now or in the future: correct plumbing leaks as soon as they are discovered; remove large trees or shrubs in areas adjacent to the foundation; install route barriers of large trees or shrubs may affect the foundation; eliminate all ponding of wateranywhere near the foundation; install guttering and downspoutswhere necessary and remove excess of water away from foundation; install subsurface drainage system if applicable; provide positive surface drainage away from the foundation. 1.12 Indemnification To the fullest extent permitted by law, the Contractor shall indemnify, defend and hold harmless Customer named on Agreement and its agents and employees, from and against claims, damages, losses and expenses, including but not limited to attorney's fees, arising out of or resulting from performance of the work or providing of materials to the extent cause in whole or in part by negligent or wrongful acts or omissions of, or a breach of this agreement by, the contractor, a subcontractor, anyone directly or indirectly employed by them or anyone whose acts they are legally responsible. 1.13 Insurance RRS represents that it has purchased and agrees that it will keep in force for the duration of the performance of the work or for such longer term as may be required by this agreement, in a company or companies lawfully authorized to do business in the State of Washington, such insurance as will protect RRS (R&R Foundation Specialist) and the owner of the site, if the site is not owned by Customer named on Agreement from claims for loss or injury which might arise out of or result from the Contractor's operations under this project, whether such operations be by RRS or by a subcontractor or its subcontractors. RRS represents and agrees that said insurance is written for and shall be maintained in an amount not less that the limits of the liability specified below or required by law, whichever coverage is greater. The Contractor certifies that coverage written on a "claims made" form will be maintained without interruption from the commencement of work until the expiration of all applicable statutes of limitation. 1) Comprehensive General Liability with limits of not less than $1,000,000.00 per occurrence. The Contractor shall file Certificates of insurance, naming the owner/person hiring the contractor as additional insured, in duplicate acceptable to all parties .n_ Priorto commencement of work, which shall contain a provision that coverages underthe policies shall not be cancelled or allowed to expire or permit material changes until at least --i/a U days written notice has been given to additional insured. Additional Terms Prices subject to change due to increased or unforeseen labor costs and/or material costs. Contractor will notify owner of any changes thereof. Contract 2. Notice to Customer F013F�1►710N I SMpausr The Notice below is required to be provided by state law; it does not create any additional causes of actions beyond breach of contract. This contractor is registered with the state of Washington, Registration No. RRFOUFS829DA and has posted with the state a bond of $12,000 forthe purpose of satisfying claims against the contractor for breach of contract including negligent or improper work in the conduct of the contractor's business. The expiration date of this contractor's registration is 03/01/2023. THIS BOND MAY NOT BE SUFFICIENTTO COVER A CLAIM THAT MIGHT ARISE FROM WORK DONE UNDER YOUR CONTRACT This bond is not for your exclusive use because it covers all work performed by this contractor. The bond is intended to pay valid claims up to $12,000 that you and other customers, suppliers, subcontractors, or taxing authorities may have. FOR GREATER PROTECTION YOU MAY WITHHOLD A PERCENTAGE OF YOUR CONTRACT You may withhold a contractually defined percentage of your construction contract as retainage for a stated period of time to provide protection to you and help insure that your project will be completed as required by your contract. YOUR PROPERT MAY BE LIENED If a supplier of materials used in your construction project or an employee or subcontractor of your contractor or subcontractor is not paid, your property may be liened to force payment and you could pay twice for the same work. FOR ADDITIONAL PROTECTION, YOU MAY REQUEST THE CONTRACTOR TO PROVIDE YOU WITH ORIGINAL "LIEN RELEASE" DOCUMENTS FROM EACH SUPPLIER OR SUBCONTRACTOR ON YOUR PROJECT. The contractor is required to provide you with further information about lien release documents if you request it. General information is also available from the state Department of Labor and Industries. SIGNATURE With my signature, I am confirming that I have read, reviewed and agreed to the proposal, job description, level survey, job photos and contract provided to me by R&R Foundation Specialist. As owner of the subject property, I authorize RRS to act as my agent. I understand that the agent may submit applications and receive correspondence on my behalf. Property Owner Name Property Owner Signature Date R&R Foundation Specialist Date RECEIVED Jul 15 2022 CITY OF EDMONDS DEVELOPMENT SERVICES DEPARTMENT